|
@@ -26,12 +26,12 @@
|
|
|
26
26
|
<li class="- topic/li ">
|
|
27
27
|
<p class="- topic/p " id="d3622e26">
|
|
28
28
|
<ph props="autonumber" class="- topic/ph ">(b)</ph>
|
|
29
|
-
If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1)by an act of the Contracting Officer in the administration of this contract, or (2)by the Contracting Officer
|
|
29
|
+
If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1)by an act of the Contracting Officer in the administration of this contract, or (2)by the Contracting Officer's failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.</p>
|
|
30
30
|
</li>
|
|
31
31
|
<li class="- topic/li ">
|
|
32
32
|
<p class="- topic/p " id="d3622e31">
|
|
33
33
|
<ph props="autonumber" class="- topic/ph ">(c)</ph>
|
|
34
|
-
A claim under this clause shall not be allowed
|
|
34
|
+
A claim under this clause shall not be allowed—</p>
|
|
35
35
|
<ol id="d3579e53" class="- topic/ol ">
|
|
36
36
|
<li class="- topic/li ">
|
|
37
37
|
<p class="- topic/p " id="d3622e37">
|