|
@@ -32,7 +32,7 @@
|
|
|
32
32
|
<i class="+ topic/ph hi-d/i ">Notice.</i> The primary purpose of this clause is to obtain prompt reporting of Government conduct that the Contractor considers to constitute a change to this contract. Except for changes identified as such in writing and signed by the Contracting Officer, the Contractor shall notify the Administrative Contracting Officer in writing promptly, within <cite outputclass="SingleLine"
|
|
33
33
|
xtrc="52.243-7_d3613e51"
|
|
34
34
|
class="- topic/cite "
|
|
35
|
-
xtrf="GFI Editable">______</cite> (to be negotiated) calendar days from the date that the Contractor identifies any Government conduct (including actions, inactions, and written or oral communications) that the Contractor regards as a change to the contract terms and conditions. On the basis of the most accurate information available to the Contractor, the notice shall state
|
|
35
|
+
xtrf="GFI Editable">______</cite> (to be negotiated) calendar days from the date that the Contractor identifies any Government conduct (including actions, inactions, and written or oral communications) that the Contractor regards as a change to the contract terms and conditions. On the basis of the most accurate information available to the Contractor, the notice shall state—</p>
|
|
36
36
|
<ol id="d3590e56" class="- topic/ol ">
|
|
37
37
|
<li class="- topic/li ">
|
|
38
38
|
<p class="- topic/p " id="d3633e40">
|
|
@@ -57,7 +57,7 @@
|
|
|
57
57
|
<li class="- topic/li ">
|
|
58
58
|
<p class="- topic/p " id="d3633e60">
|
|
59
59
|
<ph props="autonumber" class="- topic/ph ">(5)</ph>
|
|
60
|
-
The particular elements of contract performance for which the Contractor may seek an equitable adjustment under this clause, including
|
|
60
|
+
The particular elements of contract performance for which the Contractor may seek an equitable adjustment under this clause, including—</p>
|
|
61
61
|
<ol id="d3590e102" class="- topic/ol ">
|
|
62
62
|
<li class="- topic/li ">
|
|
63
63
|
<p class="- topic/p " id="d3633e66">
|
|
@@ -84,7 +84,7 @@
|
|
|
84
84
|
<li class="- topic/li ">
|
|
85
85
|
<p class="- topic/p " id="d3633e86">
|
|
86
86
|
<ph props="autonumber" class="- topic/ph ">(6)</ph>
|
|
87
|
-
The Contractor
|
|
87
|
+
The Contractor's estimate of the time by which the Government must respond to the Contractor's notice to minimize cost, delay or disruption of performance.</p>
|
|
88
88
|
</li>
|
|
89
89
|
</ol>
|
|
90
90
|
</li>
|
|
@@ -99,7 +99,7 @@
|
|
|
99
99
|
<i class="+ topic/ph hi-d/i ">Government response.</i> The Contracting Officer shall promptly, within <cite outputclass="SingleLine"
|
|
100
100
|
xtrc="52.243-7_d3613e175"
|
|
101
101
|
class="- topic/cite "
|
|
102
|
-
xtrf="GFI Editable">_____</cite> (to be negotiated) calendar days after receipt of notice, respond to the notice in writing. In responding, the Contracting Officer shall either
|
|
102
|
+
xtrf="GFI Editable">_____</cite> (to be negotiated) calendar days after receipt of notice, respond to the notice in writing. In responding, the Contracting Officer shall either—</p>
|
|
103
103
|
<ol id="d3590e177" class="- topic/ol ">
|
|
104
104
|
<li class="- topic/li ">
|
|
105
105
|
<p class="- topic/p " id="d3633e109">
|
|
@@ -119,7 +119,7 @@
|
|
|
119
119
|
<li class="- topic/li ">
|
|
120
120
|
<p class="- topic/p " id="d3633e124">
|
|
121
121
|
<ph props="autonumber" class="- topic/ph ">(4)</ph>
|
|
122
|
-
In the event the Contractor
|
|
122
|
+
In the event the Contractor's notice information is inadequate to make a decision under paragraphs (d)(1), (2), or (3) of this clause, advise the Contractor what additional information is required, and establish the date by which it should be furnished and the date thereafter by which the Government will respond.</p>
|
|
123
123
|
</li>
|
|
124
124
|
</ol>
|
|
125
125
|
</li>
|
|
@@ -131,7 +131,7 @@
|
|
|
131
131
|
<li class="- topic/li ">
|
|
132
132
|
<p class="- topic/p " id="d3633e135">
|
|
133
133
|
<ph props="autonumber" class="- topic/ph ">(1)</ph>
|
|
134
|
-
If the Contracting Officer confirms that Government conduct effected a change as alleged by the Contractor, and the conduct causes an increase or decrease in the Contractor
|
|
134
|
+
If the Contracting Officer confirms that Government conduct effected a change as alleged by the Contractor, and the conduct causes an increase or decrease in the Contractor's cost of, or the time required for, performance of any part of the work under this contract, whether changed or not changed by such conduct, an equitable adjustment shall be made—</p>
|
|
135
135
|
<ol id="d3590e235" class="- topic/ol ">
|
|
136
136
|
<li class="- topic/li ">
|
|
137
137
|
<p class="- topic/p " id="d3633e141">
|
|
@@ -148,7 +148,7 @@
|
|
|
148
148
|
<li class="- topic/li ">
|
|
149
149
|
<p class="- topic/p " id="d3633e151">
|
|
150
150
|
<ph props="autonumber" class="- topic/ph ">(2)</ph>
|
|
151
|
-
The contract shall be modified in writing accordingly. In the case of drawings, designs or specifications which are defective and for which the Government is responsible, the equitable adjustment shall include the cost and time extension for delay reasonably incurred by the Contractor in attempting to comply with the defective drawings, designs or specifications before the Contractor identified, or reasonably should have identified, such defect. When the cost of property made obsolete or excess as a result of a change confirmed by the Contracting Officer under this clause is included in the equitable adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of the property. The equitable adjustment shall not include increased costs or time extensions for delay resulting from the Contractor
|
|
151
|
+
The contract shall be modified in writing accordingly. In the case of drawings, designs or specifications which are defective and for which the Government is responsible, the equitable adjustment shall include the cost and time extension for delay reasonably incurred by the Contractor in attempting to comply with the defective drawings, designs or specifications before the Contractor identified, or reasonably should have identified, such defect. When the cost of property made obsolete or excess as a result of a change confirmed by the Contracting Officer under this clause is included in the equitable adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of the property. The equitable adjustment shall not include increased costs or time extensions for delay resulting from the Contractor's failure to provide notice or to continue performance as provided, respectively, in paragraphs (b) and (c) of this clause.</p>
|
|
152
152
|
<p class="- topic/p " id="d3633e155">
|
|
153
153
|
<term class="- topic/term ">Note:</term> The phrases "contract price" and "cost" wherever they appear in the clause, may be appropriately modified to apply to cost-reimbursement or incentive contracts, or to combinations thereof.</p>
|
|
154
154
|
</li>
|